ETENDERS

Contract notice

Information

Published

Date of dispatch of this notice: 19/01/2021

Expire date: 26/02/2021

External Reference: 2021-237337

TED Reference: 2021/S 015-030768

Contract notice

Contract notice

Directive 2014/24/EU

Section I: Contracting authority

I.1)

Name and addresses

Raidió Teilifís Éireann ( RTÉ )
8T50578M
Donnybrook
Dublin
Co. Dublin
IE
Contact person: Mark Carron
Telephone: +353 12083373
E-mail: mark.carron@rte.ie
Internet address(es):
Main address: http://www.rte.ie
Address of the buyer profile: https://irl.eu-supply.com/ctm/Company/CompanyInformation/Index/396

I.3)

Communication

The procurement documents are available for unrestricted and full direct access, free of charge, at:  
http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE
Additional information can be obtained from
the abovementioned address:  
Tenders or requests to participate must be submitted
electronically via:  http://irl.eu-supply.com/app/rfq/rwlentrance_s.asp?PID=181346&B=ETENDERS_SIMPLE
Tenders or requests to participate must be submitted
to the abovementioned address
I.4)

Type of the contracting authority

Body governed by public law
I.5)

Main activity

Recreation, culture and religion

Section II: Object

II.1)

Scope of the procurement

II.1.1)

Title

RTÉ MV Switchgear
Reference number:  20P048
II.1.2)

Main CPV code

31682300  -  Medium-voltage equipment
II.1.3)

Type of contract

Supplies
II.1.4)

Short description

RTÉ has a requirement to upgrade its existing TV Block medium voltage switchgear at its Donnybrook site. As part of this upgrade, it is planned to replace the existing MV switchboard as detailed in this tender document. This turnkey project incorporates both Civil and M&E works. A single contractor will be awarded this turnkey project and will be responsible for the Project Management of the project from Contract Award to Practical Completion.
II.1.5)

Estimated total value

Value excluding VAT: 500000.00  EUR
II.1.6)

Information about lots

This contract is divided into lots: no
II.2)

Description

II.2.2)

Additional CPV code(s)

31321200  -  Low- and medium-voltage cable
31321220  -  Medium-voltage cable
31682310  -  Medium-voltage panels
45315500  -  Medium-voltage installation work
71334000  -  Mechanical and electrical engineering services
II.2.3)

Place of performance

Main site or place of performance:  
RTÉ Donnybrook
II.2.4)

Description of the procurement

RTÉ has a requirement to upgrade its existing TV Block medium voltage switchgear at its Donnybrook site. As part of this upgrade, it is planned to replace the existing MV switchboard as detailed in this tender document. This turnkey project incorporates both Civil and M&E works. A single contractor will be awarded this turnkey project and will be responsible for the Project Management of the project from Contract Award to Practical Completion.
II.2.5)

Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents
II.2.6)

Estimated value

Value excluding VAT: 500000.00  EUR
II.2.7)

Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 6
This contract is subject to renewal: no
II.2.10)

Information about variants

Variants will be accepted: yes
II.2.11)

Information about options

Options: no
II.2.13)

Information about European Union funds

The procurement is related to a project and/or programme financed by European Union funds: no

Section III: Legal, economic, financial and technical information

III.1)

Conditions for participation

III.2)

Conditions related to the contract

Section IV: Procedure

IV.1)

Description

IV.1.1)

Type of procedure

Open procedure
IV.1.8)

Information about the Government Procurement Agreement (GPA)

The procurement is covered by the Government Procurement Agreement : yes
IV.2)

Administrative information

IV.2.2)

Time limit for receipt of tenders or requests to participate

Date:  26/02/2021
Local time:  13:00
IV.2.4)

Languages in which tenders or requests to participate may be submitted

English
IV.2.7)

Conditions for opening of tenders

Date:  26/02/2021
Local time:  13:00

Section VI: Complementary information

VI.1)

Information about recurrence

This is a recurrent procurement:  no
VI.4)

Procedures for review

VI.4.1)

Review body

The Courts Service
15 - 24 Phoenix Street
Smithfield
IE